52.211-12

Full Text

As prescribed in, insert the following clause in solicitations and contracts: (b) 11.503

Liquidated Damages-Construction (Sept 2000)

(End of clause)

If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount offor each calendar day of delay until the work is completed or accepted. (a) ____________ [] Contracting Officer insert amount

If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (b)